These Terms and Conditions govern the use of remotemobiledevs.com and any services provided through it. By accessing the website or engaging our services, you agree to these terms.
Definitions
For clarity, the following definitions apply:
- Agreement – The written contract, proposal, or accepted scope outlining services.
- Client Content – Materials supplied by the client for use within a project.
- Deliverables – Work outputs defined in the Agreement.
- Company Tools – Internal frameworks, reusable components, templates, or methodologies owned by remotemobiledevs.com.
- Final Deliverables – Completed and approved work delivered to the client.
- Project – The defined scope of services agreed between the parties.
- Services – Development, consulting, or related professional work performed.
- Third-Party Materials – Software, assets, or services not owned by us.
Delivery of Services
Services are performed according to the milestones and scope defined in the Agreement. We apply professional judgment and commercially reasonable efforts in delivering our work.
Project timelines may depend on timely client cooperation and external factors.
Proposals and Validity
Proposals remain valid for thirty (30) days unless otherwise specified. If not accepted within this period, we may revise and resubmit them.
Fees and Additional Costs
Unless expressly included in the Agreement:
- Third-party costs are billed separately.
- Approved project-related expenses may be charged at cost.
- Clients are responsible for applicable taxes related to services.
Payment Terms
Invoices are due within five (5) days unless otherwise agreed in writing. Milestone-based payment schedules may apply as outlined in the Agreement.
Late payments may result in suspension of services until outstanding balances are settled.
Changes to Scope
All change requests must be submitted in writing.
Minor changes that do not significantly impact cost or schedule may be incorporated within the existing Agreement. Significant changes require a supplemental written agreement.
Revised proposals are generally valid for fourteen (14) working days.
Delays
If delays arise due to incomplete client materials or late approvals, timelines may be extended on a day-for-day basis.
If delays occur on our side, we will inform the client promptly and seek a practical resolution.
Events beyond reasonable control, including unforeseen technical or external disruptions, are not considered breaches and may extend project timelines.
Review and Acceptance
We conduct internal quality checks before submitting Deliverables.
Clients have seven (7) working days to review and provide feedback. Reasonable revisions will be addressed within an agreed timeframe.
Client Responsibilities
Clients must provide lawful, accurate, and ready-to-use materials. They are responsible for ensuring they hold rights to supplied content.
Unless otherwise agreed, clients are responsible for final proofreading and timely decisions related to third-party services.
Attribution and Portfolio
Unless restricted in writing, we may include a discreet accreditation reference within completed projects.
We may also showcase completed work in our portfolio. Neither party should unreasonably restrict factual acknowledgment of collaboration.
Confidential Information
Both parties agree to maintain the confidentiality of non-public information. Confidential information does not include information that is publicly available or lawfully obtained.
Independent Contractor Relationship
Remotemobiledevs.com operates as an independent contractor. Nothing in these Terms creates a partnership, joint venture, employment, or exclusivity relationship unless expressly agreed in writing.
We may engage subcontractors while remaining responsible for service delivery.
Limitation of Liability
Services are provided on an “as is” basis to the extent permitted by applicable law.
Our total liability for any claim related to services is limited to the amount paid for the specific services giving rise to the claim.
Intellectual Property Rights
Upon full payment, clients receive a non-exclusive, perpetual, worldwide license to use the Final Deliverables as agreed.
Company Tools and reusable frameworks remain our property unless explicitly transferred in writing. Redistribution or modification beyond agreed use may be restricted.
Support Services
Support services are provided only if separately agreed in writing and may involve additional fees.
Any warranty may become void if Deliverables are modified by third parties without authorization.
Updates to These Terms
We may update these Terms and Conditions periodically. The version published on remotemobiledevs.com governs ongoing use. Continued use of the website or services indicates acceptance of updated terms.